TERMS OF SERVICE

Effective Date: July 13, 2026

Welcome to Samkins Construction LLC (“Samkins Construction,” “Company,” “we,” “our,” or “us”). These Terms of Service (“Terms”) govern your access to and use of our website located at https://www.samkinsconstruction.com (the “Website”), as well as any information, estimates, consultations, products, or services offered through the Website.

By accessing or using this Website, you acknowledge that you have read, understood, and agree to be bound by these Terms. If you do not agree with these Terms, please do not use our Website.

1. Company Information

Samkins Construction LLC

7051 W Strickland St

Douglasville, GA 30134

United States

Email: samkinscon@gmail.com

Phone: +1 (678) 361-7419

2. Acceptance of These Terms

By accessing this Website, submitting a contact form, requesting an estimate, scheduling a consultation, or using any services provided through the Website, you agree to comply with these Terms and all applicable federal, state, and local laws.

If you are using the Website on behalf of a business or organization, you represent that you have the authority to bind that organization to these Terms.

3. Services

Samkins Construction LLC provides residential and commercial construction services, including but not limited to:

Custom Home Construction
Home Remodeling
Home Additions
Kitchen Remodeling
Bathroom Remodeling
Roofing Services
Commercial Construction
Outdoor Living Projects
General Contracting
Renovations
Construction Consulting

The availability of specific services may vary depending on project scope, location, scheduling, permitting requirements, and other factors.

4. Estimates and Quotations

Any estimate, proposal, or quotation provided through our Website, email, telephone, or in-person consultation is provided for informational purposes only unless expressly stated otherwise in a written agreement.

Construction costs may change due to:

Material pricing fluctuations
Labor costs
Site conditions
Permit requirements
Design modifications
Client-requested changes
Unforeseen circumstances

A project is not considered accepted until both parties execute a written construction agreement.

5. Project Contracts

All construction projects are governed by a separate written construction contract.

In the event of any conflict between these Terms and an executed construction agreement, the executed construction agreement shall control.

6. Customer Responsibilities

Customers agree to:

Provide accurate project information.
Obtain timely decisions regarding selections and approvals.
Provide reasonable access to the property during construction.
Cooperate with inspections, permitting, and scheduling requirements.
Make payments according to the executed contract.

Failure to meet these responsibilities may affect project timelines or costs.

7. Permits and Inspections

Where applicable, Samkins Construction will obtain permits or coordinate permitting as specified in the construction agreement.

Government inspections and approvals are conducted by the appropriate authorities. Inspection schedules are outside our control and may affect project completion dates.

8. Change Orders

Any modifications to the original scope of work may require a written Change Order.

Change Orders may impact:

Project pricing
Completion schedule
Materials
Labor requirements

No additional work will begin until the Change Order has been approved in accordance with the construction agreement.

9. Payments

Payment schedules are established within each construction contract.

Late payments may result in:

Suspension of work
Delayed project completion
Interest or late fees where permitted by law
Collection actions as allowed by applicable law

The Company reserves all rights available under Georgia law regarding unpaid balances.

10. Warranties

Construction warranties, if provided, are governed solely by the written warranty documentation delivered upon project completion.

Nothing contained within these Terms shall expand, modify, or replace any written warranty agreement.

11. Intellectual Property

All content appearing on this Website, including but not limited to:

Logos
Branding
Graphics
Photographs
Videos
Text
Layouts
Designs
Documents
Software

is owned by or licensed to Samkins Construction LLC and is protected under United States intellectual property laws.

No content may be copied, reproduced, distributed, modified, or republished without prior written permission.

12. User Conduct

You agree not to:

Use the Website for unlawful purposes.
Attempt unauthorized access to our systems.
Introduce malware or malicious software.
Interfere with Website functionality.
Submit fraudulent information.
Violate applicable laws or regulations.

We reserve the right to restrict or terminate access for any misuse of the Website.

13. Third-Party Websites

Our Website may contain links to third-party websites for your convenience.

Samkins Construction LLC does not own, operate, or control these websites and is not responsible for their content, policies, products, or services.

Your use of third-party websites is at your own risk.

14. Electronic Communications

By contacting us through our Website, email, telephone, or online forms, you consent to receive communications related to your inquiries, estimates, projects, appointments, invoices, or customer service.

These communications may be sent electronically.

15. Disclaimer

The information provided on this Website is for general informational purposes only.

While we strive to keep all information accurate and current, we make no guarantees regarding:

Completeness
Accuracy
Availability
Suitability
Timeliness

Construction methods, pricing, materials, and product availability may change without notice.

16. Limitation of Liability

To the fullest extent permitted by applicable law, Samkins Construction LLC shall not be liable for any indirect, incidental, consequential, special, punitive, or exemplary damages arising from:

Use of this Website
Inability to use the Website
Errors or omissions
Project delays beyond our reasonable control
Third-party services
Internet interruptions

Nothing in these Terms limits liability where prohibited by law.

17. Indemnification

You agree to defend, indemnify, and hold harmless Samkins Construction LLC, its owners, officers, employees, contractors, affiliates, and representatives from any claims, liabilities, damages, costs, or expenses arising from:

Your use of the Website;
Your violation of these Terms;
Your violation of applicable law; or
Your infringement of the rights of any third party.

18. Force Majeure

Samkins Construction LLC shall not be liable for delays or failures resulting from circumstances beyond our reasonable control, including but not limited to:

Severe weather
Natural disasters
Supply chain disruptions
Labor shortages
Government actions
Utility interruptions
Pandemics
Acts of terrorism
Civil unrest

Project schedules may be adjusted accordingly.

19. Governing Law

These Terms shall be governed by and interpreted in accordance with the laws of the State of Georgia, without regard to its conflict of law principles.

20. Dispute Resolution

The parties agree to make reasonable efforts to resolve any dispute through good-faith negotiations before pursuing legal action.

If a dispute cannot be resolved informally, it shall be brought before a court of competent jurisdiction located in the State of Georgia, unless otherwise required by applicable law or agreed in writing by the parties.

21. Changes to These Terms

We reserve the right to update or modify these Terms at any time.

Changes become effective immediately upon posting to this Website unless otherwise stated.

Continued use of the Website constitutes acceptance of the revised Terms.

22. Severability

If any provision of these Terms is found to be invalid or unenforceable, the remaining provisions shall continue in full force and effect.

23. Contact Us